Home > fidic yellow book > FIDIC Yellow Book Plant and Design Build Contract

FIDIC Yellow Book Plant and Design Build Contract

FIDIC Yellow Book Plant and Design Build Contract

FIDIC Yellow Book Plant and Design Build Contract

FIDIC Yellow Book Plant and Design Build Contract 1st Edition 1999
Conditions of Contract for Plant and Design Build, which are recommended for the provision of electrical and/or mechanical plant, and for the design and execution of building or engineering works.

FIDIC Yellow Book Plant and Design Build Contract 1st Edition 1999 Under the usual arrangements for this type of contract, the Contractor designs and provides, in accordance with the Employer’s requirements, plant and/or other works; which may include any combination of civil, mechanical, electrical and/or construction works. fidic yellow book, fidic contract documents, fidic publications, fidic conditions of contract, fidic contract conditions, fidic conditions, fidic yellow book fidic contract documents fidic publications fidic conditions of contract fidic contract conditions fidic conditions

GENERAL CONDITIONS FIDIC Yellow Book Plant and Design Build Contract

1 GENERAL PROVISIONS
2 THE EMPLOYER
3 THE ENGINEER
4 THE CONTRACTOR
5 DESIGN
6 STAFF AND LABOUR
7 PLANT, MATERIALS AND WORKMANSHIP
8 COMMENCEMENT. DELAYS ANS SUSPENSION
9 TESTS ON COMPLETION
10 EMPLOYER’S TAKING OVER
11 DEFECTS LIABILITY
12 TESTS AFTER COMPLETION
13 VARIATIONS AND ADJUSTMENTS
14 CONTRACT PRICE AND PAYMENT
15 DEFAULT OF CONTRACTOR
16 DEFAULT OF EMPLOYER
17 RISK AND RESPONSBILITY
18 INSURANCES
19 FORCE MAJEURE
20 CLAIMS, DISPUTES AND ARBITRATION

Foreword FIDIC Yellow Book Plant and Design Build Contract The Fédération Internationale des Ingénieurs-Conseils (FIDIC) is publishing First Editions of four new standard forms of contract: Conditions of Contract for Construction, which are recommended for building or engineering works designed by the Employer or by his representative, the Engineer. Under the usual arrangements for this type of contract, th Contractor constructs the works in accordance with a design provided by the Employer. However, the works may include some elements of Contractor-designed civil, mechanical, electrical and/or construction works.

Conditions of Contract for Plant and Design Build or FIDIC Yellow Book Plant and Design Build Contract which are recommended for the provision of electrical and/or mechanical plant, and for the design and execution of building or engineering works. Under the usual arrangements for this type of contract, the Contractor designs and provides, in accordance with the Employer’s requirements, plant and/or other works; which may include any combination of civil, mechanical, electrical and/or construction works. Conditions of Contract for EPC Turnkey Projects, which are recommended where one entity takes total responsibility for the design and execution of an engineering project. Under the usual arrangements for this type of contract, the entity carries out all the Engineering, Procurement and Construction: providing a fully-equipped facility, ready for operation (at the “turn of the key”).

This FIDIC Yellow Book Plant and Design Build Contract is usually negotiated between the parties. fidic yellow book fidic contract documents fidic publications fidic conditions of contract fidic contract conditions fidic conditions Short Form of Contract, which is recommended for building or engineering works of relatively small capital value. Depending on the type of work and the circumstances, this form may also be suitable for contracts of greater value, particularly for relatively simple or repetitive work or work of short duration. Under the usual arrangements for this type of contract, the Contractor constructs the works in accordance with a design provided by the Employer or by his representative (if any), but this form may also be suitable for a contract which includes, or wholly comprises, Contractor-designed civil, mechanical, electrical and/or construction works. employment contract template, contract agreement contract construction contract.

18 INSURANCES
18.1 General Requirements for Insurances
18.2 Insurance for Works and Contractor’s Equipment
18.3 Insurance against Injury to Persons and Damage to Property
18.4 Insurance for Workers
Copyright by FIDIC International Federation of Consulting Engineers

ISBN  : 2-88432-023-7
Number page  : 120 page
Download FIDIC Yellow Book Plant and Design Build Contract

About these ads
  1. No comments yet.
  1. No trackbacks yet.

Leave a Reply

Fill in your details below or click an icon to log in:

WordPress.com Logo

You are commenting using your WordPress.com account. Log Out / Change )

Twitter picture

You are commenting using your Twitter account. Log Out / Change )

Facebook photo

You are commenting using your Facebook account. Log Out / Change )

Google+ photo

You are commenting using your Google+ account. Log Out / Change )

Connecting to %s

Follow

Get every new post delivered to your Inbox.

Join 74 other followers

%d bloggers like this: